THIS AGREEMENT is made at Mumbai on this 10th day of August, 2026 between SHREE GANESH COMPLEX CO-OPERATIVE HOUSING SOCIETY LIMITED, a Society registered under the Maharashtra Co-operative Society Act, under Registration No. BOM/WR/HSG/TC/10056/98-99 of 27-4-1998, and having its registered office at Sector 3, R.D.P-06, 90 Feet Road, Charkop, Kandivali (West), Mumbai – 400067, through its Hon. Chairman Mr. Rajendra Mahadeo Sawant, Hon. Secretary Mr. Sunil Bhagwant Jadhav and Hon. Treasurer Nilesh Manohar Raut, authorized pursuant to the Resolution passed in the Special General Meeting of the Society held on 15^th March 2026, hereinafter referred to as "the Society" (which expression shall, unless repugnant to the context or meaning thereof, be deemed to mean and include its office bearers and members for the time being and from time to time and their successors and assigns) of the FIRST PART;

AND

M/s. SHREE RAM KRUSHNA DEVELOPERS, a partnership firm duly registered under the Indian Partnership Act, 1932, having PAN No. AFOFS6230D, having its registered office at Office 30/A, Mhatre Plaza, M.G. Road, Kandivali (West), Mumbai - 400067, through its Authorized Partners, (1) Mr. Jubin A. Vaidya, aged 55 years, residing at A/1201 Anant Bhoomi, Mahavir Nagar, Sector 1, Kandivali West, Mumbai – 400 067 (2) Mr. Meet P. Pabari, aged 38 years, residing at 1001, 10th Floor, Laxmi Terrace, Mathuradas Road, Kandivali West, Mumbai – 400 067 (3) Mr. Pratik P. Pabari, aged 36 years, residing at 1001, 10th Floor, Laxmi Terrace, Mathuradas Road, Kandivali West, Mumbai – 400 067, hereinafter referred to as "the Developer" (which expression shall, unless it be repugnant to the context or meaning thereof, be deemed to mean and include, the partner or partners for the time being of the said firm, their respective heirs, executors and administrators) of the SECOND PART;

AND

MRS. SUNITA ABHISHEK SAWANT aged about 54 years, having PAN ABCPS1234F & MR. ABHISHEK RAMESH SAWANT aged about 62, having PAN ABCPS5678K, Indian Inhabitant having his/her address at Flat No. 204, 2nd Floor, Shree Ganesh Complex, Sector-3, Charkop, Kandivali West, Mumbai – 400067 hereinafter called "the Member/s / Purchaser/s" (which expression shall unless it be repugnant to the context or meaning thereof be deemed to mean and include his/her/their respective heirs, executors, administrators and permitted assigns only) of the THIRD PART.

AND

MR. ROHAN ABHISHEK SAWANT aged about 26 years, having PAN ABCPS9012L Indian Inhabitant having their address at Flat No. 204, 2nd Floor, Shree Ganesh Complex, Sector-3, Charkop, Kandivali West, Mumbai – 400067 hereinafter called "the Purchaser/s" (which expression shall unless it be repugnant to the context or meaning thereof be deemed to mean and include his/her/their respective heirs, executors, administrators and permitted assigns only) of the FOURTH PART.

Whereas

1. The Society is the owner of the property being "all that piece and parcel of land bearing CTS No. 197A, 198A & 198B, admeasuring about 2217.30 sq. mtrs. comprising of four Wings i.e. A, B, C and D, standing therein knows as "Shree Ganesh Complex" ["Existing Buildings"] consisting of 60 (Sixty) residential flats of Village Kandivali, RDP No. 6, Taluka Borivali, District Mumbai, Sector No.3, Charkop, Kandivali (West), Mumbai – 400067" hereinafter referred to as the ("said property") and as more particularly described in the First Schedule hereunder written.
2. The Society being desirous of re-developing the said property, in Special General Meeting of the Society held on 7^th August 2022, resolved unanimously for redevelopment of the said property by demolishing the existing building and constructing new building/s by using, consuming, loading etc., the entire Development Rights as per the DCPR- 2034.
3. Pursuant thereto, under a Development Agreement dated 21^st April 2026 ("Development Agreement") and Supplementary Development Agreement dated 5th June 2026 ("Supplementary Development Agreement") executed by and between the Society herein (therein also referred to as the "Society") of One Part and Shree Ram Krushna Developers, the Developer herein (therein also referred to as the "Developer") of the Other Part; the Society granted the development rights with respect to the said property in favour of the Developer therein for the consideration and on terms and conditions more particularly stated in the Development Agreement and Supplementary Development Agreement. The said Development Agreement is duly registered with Sub-Registrar of Assurance, Borivali- Taluka, Mumbai on 21^st April 2026 under Sr. No. MB17-7498-2026 and the Supplementary Development Agreement is duly registered with Sub-Registrar of Assurance, Borivali- Taluka, Mumbai on 5th June 2026 under Sr. No. MB17-8123-2026. The copy of the Index – II of the said Development Agreement is hereto annexed and marked as Annexure 'A'.
4. Pursuant to the said Development Agreement, the Society has also executed a Power of Attorney in favour of the partners of the Developer herein inter alia to enable them to develop the said Property. The said Power of Attorney is also registered with Sub-Registrar of Assurances, Borivali Taluka on 21^st April 2026 under Sr. No. MB17-7500-2026 ("Power of Attorney").
5. In terms of the said Development Agreement and the Supplementary Development Agreement, the Developer is authorised to develop the said property and provide the members with new flats on ownership basis as and by way of Permanent Alternate Accommodation and free of all costs.
6. Pursuant to the said Development Agreement and the Supplementary Development Agreement, the Developer has got plans and specifications sanctioned from the MCGM and have obtained the part IOD bearing No. CE/1234/BP(WS)/AP dated 15th June 2026. The copy of the part IOD is annexed hereto and marked as Annexure "B".
7. The Society has allotted to the Member/s herein 10 Shares of Rs. 50/- each, bearing distinctive numbers from 371 to 380 under share certificate No. 38 Dt. 01/11/2016 ("said Shares"). By virtue of holding membership rights in the said Society, the said Member/s is also owner of Flat No. 204 on the 2nd floor, admeasuring about 450 Sq. ft. Carpet in the building known as "Shree Ganesh Complex", situated at Sector No.3, Charkop, Kandivali (West), Mumbai – 400067 ("said Old Premises") and is more particularly described in the Second Schedule hereunder written.
8. The Developer shall also provide to the Member/s herein, the fittings and amenities in his/her/their New Flat Free of Costs which is more particularly set out in the Annexure "C" attached hereto.
9. The Member/s has agreed to accept as and by way of Permanent Alternate Accommodation a flat in the new building to be constructed by the Developer on the said property, and the Society has agreed to such an allotment of flat to the Member/s.
10. The parties hereto are desirous of recording the said terms and conditions agreed between them as hereinafter appearing:

Now This Agreement Witnesseth And It Is Hereby Agreed By And Between The Parties Hereto As Under

1. The recitals contained hereinabove, the terms contained in the Development Agreement, Supplementary Development Agreement and the Annexures herein shall form an integral part of this Agreement as if the same were set out and incorporated herein.
2. The Member/s declares that he/she/they is/are the owner with respect to the said Old Premises and is in use, occupation and possession of the said Old Premises and are using for the purpose of residence and the said old premises is free from any encumbrances, mortgages and litigations.
3. The Member/s declares that he/she/they is/are the only person entitled to the said old premises and that he/she/they is/are entitled to enter into this agreement and that save and except the Member/s herein no other person has any share, right, title, interest, claim or demand of any nature whatsoever into or upon the old premises or any part or portion thereof including by way of sub-tenancy, leave and license, inheritance, caretaker, lease, sub-lease etc. The Member/s hereby agree/s to get the N.O.C. from the person or persons claiming through him and further agrees to indemnify the Developer against any loss which may be sustained by the Developer and/or expenses that may be incurred for defending any action brought about by such person or persons.
4. The Member/s has/have agreed to accept as and by way of Permanent Alternate Accommodation on ownership basis in lieu of the said Old Premises, a residential Flat on the said Property in accordance with the terms and conditions under the Development Agreement dated 21st April 2026. And Supplementary Development agreement Dated 5th June 2026. Accordingly, the Developer has agreed to allot RERA Carpet Area of 595 Square Feet i.e equivalent to MOFA carpet area being the existing Carpet Area of the Existing Members' respective premises plus additional MOFA carpet area of 33% (Thirty Three Percent) over and above the existing carpet area inclusive of fungible area in the proposed new building to be constructed on the said property and to be known as "Shree Ganesh Complex".
5. [This clause is blank in the original source draft — no text was provided for Clause 5. Please insert the intended clause content before circulation / execution of this Agreement.]
6. The Member/s/Purchaser/s have expressed their intention to purchase and the Developer has agreed to sell an additional area admeasuring 31 Square feet RERA carpet area ("Additional Purchase Area") at an agreed rate of Rs.20,000/- per square feet to be paid aggregating to Rs. 6,20,000/- as per the Schedule of Payment hereinbelow:

   Sr. No.	Payment Stage	%
   1	At the time of Booking	10%
   2	At the time of Development Agreement	10%
   3	Before the execution of PAAA	10%
   4	Completion of Plinth level	10%
   5	Completion of 3rd Parking Podium Slab	5%
   6	Completion of 6th Parking Podium Slab	5%
   7	Completion of 8th Residential Slab	4%
   8	Completion of 10th Residential Slab	4%
   9	Completion of 12th Residential Slab	4%
   10	Completion of 14th Residential Slab	4%
   11	Completion of 16th Residential Slab	4%
   12	Completion of 18th Residential Slab	4%
   13	Completion of 20th Residential Slab	4%
   14	Completion of 22nd Residential Slab	4%
   15	Completion of Overhead Tank	3%
   16	Completion of Internal Plaster Work	3%
   17	Completion of External Plaster Work	3%
   18	Completion of Lifts, water pumps, electrical fittings, electro, mechanical and environmental requirements, entrance lobby/s, plinth protection, paving of areas appertain	4%
   19	On receipt of Occupation Certificate or Possession whichever earlier	5%
   Total		100%

   It is agreed by the Member that the said consideration is exclusive of all other expenses and charges. It is expressly agreed that the said transaction shall automatically attract all expenses, duties, taxes, including goods and service tax (GST), stamp duty, registration charges and development charges in relation to the purchase of additional purchase area which shall be borne by the Member/s and Purchaser/s.

7. As such, the Developer shall provide the Member/s and Purchaser/s jointly with a new flat in all admeasuring 626 sq. ft. RERA carpet area [including the additional area agreed to be acquired by the Member/s as aforesaid] in the proposed new building to be constructed on the said property and to be known as "Shree Ganesh Complex" to be constructed on the said Property (hereinafter referred to as "the new flat").
8. Accordingly, the Developer shall allot Flat No. 1604 on the 16^th floor in the new building to be constructed by the Developer aggregating to 626 Square Feet RERA Carpet Area (hereinafter referred to as "the New Flat" and more particularly described in Third Schedule hereunder written). A typical floor plan is annexed hereto as Annexure "D" to this Agreement.
9. The Developer has agreed to provide and allot to the Member/s and Purchaser/s jointly herein the said New Flat along with one (01) car parking space, which shall be allocated at the podium level, as per terms of the Development Agreement.
10. It is agreed that the said New Building as well as the New Flat shall have such amenities and facilities of such specifications as set out in Annexure "O" of the said Development Agreement.
11. The Developer has agreed to provide the said Permanent Alternate Accommodation that is the said New Flat with occupation certificate in the proposed New Building as per the allotment of flats made by the Society, with the consent of the Member/s and which is evidenced from the Society being a Confirming Party to these presents.
12. The Member/s shall within 45 (forty-five) days from the date of receipt of notice for vacation after part IOD, hand over the vacant and peaceful possession of the said old Premises to the Developer.
13. The Developer shall pay Rent/Displacement Compensation, Hardship Compensation, Brokerage, Shifting Charges in terms of Clause Nos. 6 and 13 of the said Development Agreement and Supplementary Development Agreement.
14. The Developers hereby agree, declare and confirm that:
    1. The Developer alone shall bear and incur and pay all costs, charges, expenses, premiums and the construction cost in respect of the said New Flat.
    2. Proceed and/or commence to develop the said property at their own costs and at their own risk and on their own account, to the utmost extent permissible by constructing new building and for that purpose shall engage at their own costs, their own Architects, R.C.C. Consultants, Security personnel and other professional for supervising the construction work, and shall pay and bear all other incidental charges and costs for carrying out and completing the construction work and the matters connected with the said property and the development thereof.
    3. The Developer alone shall pay all the amounts payable including in the nature of refundable deposits to the MCGM for obtaining requisite approvals for building plans. In case the amount/s of any of such deposits is refunded by the concerned authorities in the name of the Society, the Society shall be liable to hand over / reimburse all such amount/s to the Developers promptly.
15. The Developer has agreed with the Society that:-
    1. The Developer will, subject to force majeure circumstances, construct the new building and handover possession of the said New Flat to the Member and Purchaser/s with part/full Occupation Certificate from the concerned authority within a period of 30 (Thirty) months with the further grace period of 6 months i.e. 36 (Thirty-Six) months, from the date of Developer obtaining the First Commencement Certificate for the construction of the new building/s on the said Property. However, in case of force majeure circumstances set-out in the Development Agreement, the said period shall stand duly extended in the manner and following the procedure as set-out in the Development Agreement.
    2. In case the project travels beyond the period of 36 (Thirty-Six) months, in that case, the Developer shall pay the enhanced Rent/Displacement Compensation, as per Clause No. 13.1.2 and 13.1.3 of the Development Agreement and shall also pay an additional Brokerage charges in terms of Clause No. 13 of the said Development Agreement.
16. On completion of construction of the new building and after obtaining the occupation certificate (full/part) from the MCGM, the said Developer shall notify the Member/s and Purchaser/s to take possession of the flats in the Members allocation. The Member/s and Purchaser/s shall occupy the said New Flat immediately or within 30 (thirty) days of the Developer giving written notice to the Society intimating that the New Flat is ready for use and occupation and that the Developer has received the Occupation Certificate (full/part) from the Municipal Corporation of Greater Mumbai. It is clarified that in case of part Occupation Certificate, the Developer shall, prior to issuing notice for occupation, ensure that the portion of the new Building for which part Occupation Certificate is received includes the New Flat.
17. Subject to Clause 14 above, if the Member/s and Purchaser/s fails to take possession of the said New Flat, then the Developer shall be discharged from the said liability/obligation to make payment towards the monthly transit rent thereafter.
18. It is agreed and declared that at the time of taking possession of the said New Flat in the newly constructed building, the Member/s shall refund balance amount of rent/displacement compensation, if any, to the Developers which is received (by several PDCs or NEFT) for procuring his/her/their temporary alternate accommodation. Prior to taking possession of the said New Flat, the Member/s and Purchaser/s shall inspect the same thoroughly and confirm that the same is without any defect in amenities and facilities.
19. On expiry of the Possession Date which is 30 days from the date of Occupation Certificate, the Member/s and Purchaser/s shall be bound to take possession of the said New Flat and all outgoings without limitation of maintenance charges, municipal taxes, property tax, cess, taxes etc., with respect to the said New Flat shall be borne and paid by the Existing Members and Purchaser/s and the Developer shall not be liable or responsible for payment of such outgoings thereafter with respect to the said New Flat.
20. The Parties Agree that the Developer shall pay all cost, charges and expenses in respect of new connection or restoration of connection of Adani Electricity Mumbai Ltd./Tata Power Company Ltd., Mahanagar Gas Ltd., and their meters before handing over the possession of New Flat. However, the Member/s and Purchaser/s will have to pay for the deposits and other charges, if any, that are required to be paid to these Service Providers for obtaining such fresh connections, on the basis of actual. The Developer shall endeavour to procure Mahanagar Gas connection within a period of 6 months after receipt of Full OC. The Developer shall apply to Mahanagar Gas Ltd. within 1 (one) month of obtaining CC subject to approval of MCGM or any other relevant statutory authorities.
21. The Member/s and Purchaser/s himself/ herself/ themselves with intention to bring all persons into whomsoever hands the said New Flat may come doth hereby covenant with the Developers as follows:
    1. To maintain the said New Flat at Member/s and Purchaser/s own cost repair and keep in good tenantable repair and condition from the date of possession of the said New Flat and shall not do or suffer to be done anything in or to the building in which the said New Flat is situated, balconies, elevation-projections, staircase or any passages which may be against the rules, regulations or byelaws or concerned local or any other authority or change/alter or make addition in or to the building in which the said New Flat is situated and the said New Flat itself or any part thereof.
    2. Not to store in the said New Flat any goods which are of hazardous, combustible or dangerous nature or are so heavy as to damage the construction or structure of the building in which the New Flat is situated or storing of which goods is which are objected to by the concerned local or other authority and shall not carry or cause to be carried, carry heavy packages which may damage other floors or are likely to damage the stair cases, common passages or any other structure of the building in which the said New Flat is situated, including entrances of the building in which the said New Flat is situated and in case any damage is caused to the building in which the said New Flat is situated on account of negligence or default of the Member/s in this behalf, the Member/s and Purchaser/s shall be liable for the cost and consequences of the said breach.
    3. To carry at his/her/their own cost all internal repairs to the said New Flat and maintain the said New Flat in the same conditions, state and order in which it was delivered by the Developers to the Member/s and Purchaser/s and shall not do or suffer to be done anything in or the building in which the said New Flat is situated or the said New Flat which may be governed with the rules and regulations and bye-laws of the concerned local authority to other public authority. In the event of any Member/s committing any act in contravention of the above provision, the said Member/s shall be responsible and liable for the consequences thereof to the concerned local authority and/or other public authority.
    4. Not to (a) demolish or cause to be demolished the said New Flat or any part thereof or at any time, (b) make or cause to be made any addition or alteration of whatever nature in or to the said New Flat or any part thereof, (c) make/carry out any alteration in the elevation and outside colour schemes of the building in which the said New Flat is situated and shall keep the portion, sewers, drains, pipes in the said New Flat and appurtenances thereto in good tenantable repair condition and in particular so as to support shelter and protect the other parts of the building in which the said New Flat is situated, and (d) chisel or in any other manner damage columns, beams, walls, slabs or RCC Pardis or make any other structural alterations in the said New Flat without the prior written permission of the Developer and/or the Society.
    5. Not to do or permit to be done any act or thing which may render void or voidable any insurance of the said land or the building in which the said New Flat is situated or any part thereof or whereby any increased premium shall become payable in respect of the insurance.
    6. Not to throw dirt, rubbish, rags, garbage, etc. nor permit the same to be thrown from the said New Flat in the compound or any portion of the said land and the building in which the said New Flat is situated.
    7. To bear and pay increase in local taxes, water charges insurance and such other levies, if any, which are imposed by the concerned local authority and/or Government and/or other public authority or on account of change of user of the said new shop/ office by the Member/s or otherwise.
    8. The Member/s and Purchaser/s shall observe and perform all the rules and regulations which the Society may adopt and the additional alteration or amendments thereof that may be made from time to time for protection and maintenance of the said new building and the said New Flat therein and shall pay and contribute regularly and punctually towards the taxes, expenses or other outgoings in accordance with the terms of this Agreement and rules and regulations laid down by the Society.
    9. To allow the Developers with their servants and agents in the said New Flat or any part thereof to carry out the necessary repairs to the building and/or the New Flat.
    10. To ensure that no nuisance/ annoyance/ inconvenience is caused to the other occupants of the proposed building by any act of the Member/s.
    11. The Member/s undertake/s not to enclose any passage/s, lobby or other common areas in the proposed Building in any manner whatsoever.
22. It is agreed that after possession of the Permanent Alternate Accommodation is taken from the Developers, the Member/s and Purchaser/s shall not do any act or thing which will spoil, change the elevation/ exterior of the new building.
23. The Member/s and Purchaser/s shall not use the said New Flat or permit the same to be used for any purpose whatsoever other than the purpose for which it is allotted.
24. All notices/correspondence to be served on the Member/s and Purchaser/s as contemplated by this agreement shall be deemed to have been duly served if sent to the Member/s by Regd. A.D./courier at their address mentioned below.

    Address of the Member/s and Purchaser/s

    Mrs. Sunita Abhishek Sawant, Mr Abhishek Ramesh Sawant & Mr Rohan Abhishek Sawant

    Flat No. 204, Shree Ganesh Complex, Sector -3, Charkop, Ganesh Chowk, Kandivali West, Mumbai – 400067

    Mobile No.: +91 98200 12345

    Email Id: abhishek_sawant@outlook.com

    Address of the Developer

    SHREE RAM KRUSHNA DEVELOPERS

    30/A, Mhatre Plaza, M G Road, Dahanukarwadi, Kandivali West, Mumbai-400067

    Email Id: info@ramkrushnadevelopers.com

25. During the subsistence of this Agreement, only with the prior written approval from the Society, the Member/s and Purchaser/s shall be entitled to sell and/or transfer their rights under these presents to a third party, subject however that the Society hereby undertakes not to transfer the said New Flat in its records unless the new transferee executes Deed of Adherence in favour of the Society and furnishes a copy thereof to the Developer. The New Flat purchaser i.e. the Transferee, shall exercise all the rights of his/her predecessor including the benefits that such vendor was entitled to as per the terms of this Development Agreement and Supplementary Deed and Individual Tripartite Agreement executed between the parties. The New Flat purchaser i.e. the Transferee shall be deemed to be obliged to abide with all the terms and conditions of these present. It is clarified that in the event if there are any outstanding amount payable towards purchase of any extra area by any Existing Member and Purchaser/s, if he/she has opted to purchase such extra area to the Developer, then prior written consent shall be obtained by such Existing Member and Purchaser/s from the Developer before such Member seeks to sell his/her/their flat to any third-party. However, the Society shall be entitled to transmit the shares of any of its Existing Members in the event of death of any member, with intimation thereof to the Developer.
26. In the event of any dispute, differences, non-compliance or non-payment arising between the parties hereto with regard to these presents or interpretation thereof and which cannot be mutually resolved within 90 (Ninety) days by mutual discussion/s, the same shall be referred to the Arbitration before a Sole Arbitrator to be appointed by the parties jointly by mutual consent. The Arbitration shall be held under the provisions of the Arbitration and Conciliation Act, 1996 or any statutory modification thereof. The seat and venue of the Arbitration shall be Mumbai and shall be conducted in English Language. The decision of the Arbitrator shall be final and binding upon the Parties.
27. The Society/members and the Developer herein agree and confirm that the Development Agreement, Supplementary Development Agreement and the Power of Attorney are valid and subsisting and binding upon the parties hereto and they confirm all the clauses and statements made herein.
28. It is further agreed that the various clauses of the Development Agreement and Supplementary Development Agreement shall ipso-facto be applicable in this Agreement and shall be deemed to have been incorporated verbatim, save and except to the extent of the modification (if any) herein contained.
29. It is further agreed that the Developer shall rectify/repair any leakages/defect in the new building, that will be pointed out by the Society and/or the members after obtaining Full occupation Certificate of the flats in the new building, provided however that if such leakages are occurred on account of any additions/alterations made by any member of the Society in his/her, flat, the Developers shall not be liable to carry out repairs occurring in the said Building due to such additions and alterations. The Developers alone shall be responsible for attending to any structural or any other defects in the construction if the same is found during a period of defect liability from the date of obtaining Occupation Certificate and handing over possession of the newly constructed flats and completion of the said new buildings and shall attend to all the structural including water proofing defects in construction as may be pointed out by the concerned member or the society, except for the damages caused due to negligence or illegal additions and alterations made by the member.
30. The expenses by way of stamp duty and registration charges payable on this Agreement for allotment of the said New Flat with new area to be provided free of costs by the Developer, shall be paid by the Developer alone and the Developer shall bear and pay advocates fees and other expenses. If the Member/s has/have opted to purchase Additional Area then in that event, the Member/s and Purchaser/s shall be liable to pay the GST on such Additional Area and also the proportionate stamp duty, development charges, registration charges and any other charges as may be applicable in regard to such Additional Area agreed to be acquired by him/her/them and it is expressly agreed that the Developer shall not be liable for the same.
31. The name of the new residential building shall be "Shree Ganesh Complex". However, the name of the Society shall remain "Shree Ganesh Complex Cooperative Housing Society Limited".

The First Schedule Herein Above Referred To

("The Said Property")

All that piece and parcel of land admeasuring 2217.30 sq. mtrs. out of the total area of Larger Plot more particularly described in the First Schedule hereinabove and bearing CTS No. 197A, 198A & 198B of Village Kandivali, RDP No.6, Taluka Borivali, District Mumbai, Sector No.3, Charkop, Kandivali (West), Mumbai – 400067, together with the buildings standing thereon and known as "Ganesh Complex" comprising of 4 wings i.e. A, B, C & D, each having ground plus 4 (Four) upper floors and in all consisting of 60 flats and bounded as follows:

On or towards the East	–	Shree Ganesh Gaurav CHSL
On or towards the West	–	CTS No. 1C/1/397
On or towards the North	–	CTS No. 290, 291, 132 – 139
On or towards the South	–	90 Feet Road

The Second Schedule Herein Above Referred To

("The Said Old Premises")

Flat No. 204 on the 2nd floor, admeasuring about 450 Sq. ft. Carpet in the building known as "Shree Ganesh Complex", situate at Sector 3, R.D.P-06, 90 Feet Road, Charkop, Kandivali (West), Mumbai – 400067 and standing on the property more particularly described in the First Schedule hereinabove mentioned.

The Third Schedule Herein Above Referred To

("The Said New Flat")

ALL THAT Flat No. 1604 on the 16^th floor and admeasuring 626 Sq. ft. Carpet Area (inclusive of fungible area (if Any) and Additional Purchase area in the New Building to be constructed and known as Shree Ganesh Complex on the property more particularly described in First Schedule above referred to.

IN WITNESS WHEREOF the parties hereto set and subscribed their hand on the day, month and year first hereinabove written.

Signatures